CITY of RAPID CITY Agenda Item Summary
Public Works Committee Meeting Date: 4/30/2013		City Council Meeting Date: 5/6/2013
Staff Contact: Stacey Titus		Petitioner: Click here to enter text.
Location: West of Sagewood Street
Agenda Title:
Authorize Mayor and Finance Officer to Sign Amendment No. 2 to an Agreement between the City of Rapid City and Banner Associates Inc. for Professional Services for Northridge Water Storage Reservoir, Project No. W09-1792 / CIP No. 50754, in the amount of $66,792.00.
Summary:
The project has been delayed approximately 11 months due to problems associated with the prime contractor’s painting sub-contractor. The painting sub-contractor failed to comply with project drawings and specifications. The consultant had to duplicate services and expend additional effort as a result of these delays. In addition, the City of Rapid City requested additional start-up services associated with the Northridge Water Booster Station project.
Funding Source & Fiscal Impact (if applicable):
0602/0934 – Water Expansion
Recommendation:
Action: Choose an item. Approve Notes: Click here to enter text.
Options:
Click here to enter text.
Attachments & Links:
Agreement	Project Location Map		Click here to enter text.
Click here to enter text.	Click here to enter text.		Click here to enter text.
Click here to enter text.	Click here to enter text.		Click here to enter text.